{"product_id":"revised-gutter-installation","title":"Revised Gutter Installation","description":"\u003cp\u003eRevised gutter installation price. Total $4,185. Paid by homeowner $1,425, $700, $600 2,825. Leaving a balance of 1,860 to be paid upon completion of the job.  10% discount, leaving a balance of $1,474. \u003cbr\u003e\u003cbr\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003e\u003cem\u003e\u003cstrong\u003eTERMS \u0026amp; CONDITIONS\u003c\/strong\u003e\u003c\/em\u003e\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cstrong\u003e1. PAYMENT TERMS\u003c\/strong\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003ePayment for all approved additional repair work, including The remaining balance for the original gutter installation c Accepted payment methods may include cash, certified funds,\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cstrong\u003e2. CHANGE ORDERS \/ UNFORESEEN CONDITIONS\u003c\/strong\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eAny hidden damage, structural deficiencies, wood rot, water Additional work required due to unforeseen conditions must t Discovery of hidden damage requiring repair shall not be cor\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cstrong\u003e3. RIGHT TO SUSPEND WORK\u003c\/strong\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eContractor reserves the right to suspend or delay work if:\u003c\/span\u003e\u003c\/p\u003e\n\u003cul\u003e\n\u003cli\u003e\u003cspan\u003ePayment obligations are not met\u003c\/span\u003e\u003c\/li\u003e\n\u003cli\u003e\u003cspan\u003eUnsafe site conditions exist\u003c\/span\u003e\u003c\/li\u003e\n\u003cli\u003e\u003cspan\u003eAdditional hidden damage prevents proper installation\u003c\/span\u003e\u003c\/li\u003e\n\u003cli\u003e\u003cspan\u003eMaterials or repairs necessary to safely complete work are\u003c\/span\u003e\u003c\/li\u003e\n\u003c\/ul\u003e\n\u003cp\u003e\u003cspan\u003eAny suspension caused by customer nonpayment or refusal to a\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cstrong\u003e4. LATE PAYMENTS\u003c\/strong\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eInvoices not paid within five (5) calendar days of issuance\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eCustomer agrees to pay all reasonable costs of collection, i\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cstrong\u003e5. MATERIALS \u0026amp; WORKMANSHIP\u003c\/strong\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eContractor agrees to furnish labor and materials in a professional Contractor is not responsible for pre-existing structural deficiencies, concealed damage, mold, pest damage, prior improper repairs, or damage is caused by weather, events or conditions outside contractor control.\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cstrong\u003e6. PROPERTY ACCESS\u003c\/strong\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eCustomer agrees to provide contractor reasonable access to t Any delays caused by restricted access, customer scheduling\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cstrong\u003e7. PERMITS \/ CODE COMPLIANCE\u003c\/strong\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eUnless specifically stated otherwise in writing, pricing doe\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eAny work required solely due to existing code violations\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cstrong\u003e8. LIMITATION OF LIABILITY\u003c\/strong\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eContractor liability shall be limited to the value to the value of services actually performed under this agreement.\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eContractor shall not be liable for indirect, incidental, consequential, or special damages, including loss of use, water intrusion from pre-existing conditions, or delays caused by weather, suppliers, or hidden structural defects.\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cstrong\u003e9. GOVERNING LAW\u003c\/strong\u003e\u003c\/p\u003e\n\u003cp\u003e\u003cspan\u003eThis agreement shall be governed by and interpreted in accordance with laws of the Commonwealth of Virginia. \u003cbr\u003e\u003c\/span\u003e\u003c\/p\u003e\n\u003cp\u003eAny dispute arising from the agreement shall be resolved in the appropriate court of competent jurisdiction, located in Virginia.\u003c\/p\u003e\n\u003cp\u003e \u003c\/p\u003e\n\u003cp\u003eSignature ___________________\u003c\/p\u003e\n\u003cp\u003eDate________________\u003c\/p\u003e","brand":"EliminatesPro","offers":[{"title":"Default Title","offer_id":52442791969044,"sku":null,"price":1474.0,"currency_code":"USD","in_stock":true}],"thumbnail_url":"\/\/cdn.shopify.com\/s\/files\/1\/1008\/1707\/6500\/files\/IMG_0301.jpg?v=1777648366","url":"https:\/\/eliminatespro.myshopify.com\/products\/revised-gutter-installation","provider":"EliminatesPro","version":"1.0","type":"link"}